Government Contract | Texas
Wortham House Renovation

Bid Information

Bid Alert No: 00000481102

Bid Title: Wortham House Renovation

Agency Bid No. Title: RFP730-16074

Received Date: 02/09/2016

Close Date: 02/26/2016

Purchase Type: Not Stated

Delivery Point: University of Houston, Houston, Texas

Delivery Date: Not Stated

Special Notices: Pre-Bid Conference Mandatory 02/15/2016 09:00 AM, Questions Due By Optional 02/17/2016 02:00 PM


Specifications include, but are not limited to: The Project involves all labor, equipment, materials, and supplies required for [Door Replacement, Window Replacement, Stucco Repairs & Exterior Paint] in the Building in accordance with the drawings and specifications prepared by [PBK ARCHITECTS, INC.] (the Project Architect ) dated [1-25-2016], a copy of which is attached hereto and incorporated herein as Exhibit A. Substantial Completion of the Project shall occur on or before [7-15-2016], time being of the essence.Scope of Services, Acceptance of Contract Terms: As further described in Owners standard form Owner-Contractor Agreement (the Contract Form ), which is published online at the respondent to this RFP (each, a Respondent ) that is ultimately awarded the contract (if any) for the Project ( Contractor ) will provide construction services necessary to complete the Project within budget and on schedule. BY SUBMITTING A PROPOSAL, RESPONDENT IS EXPRESSLY CONSENTING TO THE TERMS, CONDITIONS AND PROVISIONS OF THE CONTRACT FORM. Any capitalized term used but not defined in this RFP has the meaning ascribed to it in the Contract Form.

Product Codes: 90937, 91079, 91014, 91015, 91080, 91480

Agency Information

Issuing Agency: University of Houston

State: Texas

Agency Type: State and Local

Contact: Tim Henry Purchasing Department, 5000 Gulf Freeway, Bldg. 1, #201, Houston, Texas, 77023




FREE Market Analysis

Get a FREE 90-Day Market Analysis and see the bids you’ve been missing