Government Contract | Texas

Bid Information

Bid Alert No: 00000470351


Agency Bid No. Title: RFP730-16067

Received Date: 01/27/2016

Close Date: 02/15/2016

Purchase Type: Substantial Completion December 15, 2017

Delivery Point:

Delivery Date: Not Stated

Special Notices: Pre-Bid Conference Optional 02/03/2016 02:00 PM, Questions Due By 02/08/2016


Specifications include, but are not limited to:General. The University of Houston System (Owner) is soliciting Proposals (as defined below) fortheselectionofaConstructionMan a g e r a t R i s k ( C M a R ) f o r t h e S o p h o m o r e S t u d e n t H o u s i n g B u i l d i n g ( t h e P r o j e c t ) o n t h e c a m p u s o f t h e U n i v e r s i t y o f H o u s t o n -Victoria. A CMaR that wishes to b e c o n s i d e r e d f o r t h e a w a r d o f a c o n t r a c t f o r t h e S e r v i c e s ( e a c h , a Respondent) must submit its proposal for such award (the Proposal) in compliance with the requirements contained in this RFP. Failure to so comply will result in disqualification of the Proposal and the Respondent. 1.2 Project Description. The project will consist of two separate but connected areas sharing common study labs and computer labs. The Student Center will include a bookstore, food court, office space, Student Government space, study labs, and small and large group areas. The Learning Commons will include library and study space. It is desired that surface parking of 150-200 spaces be provided. The Project will be sited on a two-acre tract of land directly across from the campus, on Ben Wilson Street. The campus map can be accessed here: University of Houston-Victoria | Campus Map 1.3 Cost, logistics, and preliminary milestone schedule 1.3.1 The Construction Cost Limitation (CCL) for the Sophomore Student Housing Building Project is $19,000,000. The Construction Contingency is 5 % of the work. This CCL does not include IT / Security Equipment, Audio Visual (AV) Equipment, or Furniture, Fixtures and Equipment (FFE). 1.3.2 See Project Schedule Section 1.6 1.4 Scope of services; acceptance of contract terms are as further described in Owners standard form Construction Manager-at-Risk Agreement (the Contract Form ) a copy of which may be found online at contracts-and-forms/. Construction Manager will provide all Pre-Construction Phase and Construction Phase services necessary to complete the Project on schedule and within budget. Any capitalized term used but not defined in this RFP has the meaning ascribed to it in the Contract Form. B Y SUBMITTING A P ROPOSAL , YOU ARE EXPRESSLY AGREEING TO THE TERMS OF THE C ONTRACT F ORM , WHICH TERMS ARE INCORPORATED HEREIN FOR ALL PURPOSES . 1.4.1 Project pricing shall include a base scope, with both additive and deductive Alternates. Alternates will be developed during the design process and will likely be related to shell space build-out, infrastructure for future growth, etc

Product Code: 95826

Agency Information

Issuing Agency: University of Houston

State: Texas

Agency Type: State and Local

Contact: Maya Thornton 311 E. Cullen, 4800 Calhoun, Houston, Texas, 77204

Phone: 713-743-8269




FREE Market Analysis

Get a FREE 90-Day Market Analysis and see the bids you’ve been missing