Government Contract | Texas

Bid Information

Bid Alert No: 00000440052


Agency Bid No. Title: RFP730-16052

Received Date: 12/15/2015

Close Date: 01/15/2016

Purchase Type: Substantial Completion July 13, 2018

Delivery Point:

Delivery Date: Not Stated

Special Notices: Questions Due By 12/21/2015 03:00 PM


Specifications include, but are not limited to:1.1General The University of Houston System (Owner) is soliciting proposals (Proposals) from theshortlisted r e s p o n d e n t s ( e a c h a Respondent) to the Request for Qualifications number RFQ 730- 16008 issued by Owner on October 5, 2015 (the RFQ) for the constr uction of the University of Houston-Clear Lake Recreation and Wellness Center (the Project). 1.2 Cost, logistics, and preliminary milestone schedule 1.2.1 The Construction Cost Limitation (CCL) for the Recreation and Wellness Center Project is $29,137,500. This CCL includes $1,387,500,000 Contractor Contingency (5 %). This CCL does not include IT / Security Equipment, Audio Visual (AV) Equipment, or Furniture, Fixtures and Equipment (FFE). 1.2.2 T h e a r e a i d e n t i f i e d a s P R O J E C T S I T E i n E X H I B I T C , a c o p y o f w h i c h i s a t t a c h e d hereto and incorporated herein for all purposes, will be available for all construction activities as noted. The Respondent awarded the contract for the Project (the Construction Manager) will be allowed limited parking on-site for project management and supervision personnel. All other Construction Manager employees, subcontractors, consultants, agents and representatives are required to park at more remote parking areas otherwise designated on campus. Parking is provided by Owner at no cost to the Construction Manager and no costs will be accepted in this category of General Conditions. 1.2.3 See Project Schedule Section 1.5 1.3 Scope of services; acceptance of contract terms are as further described in Owners standard form Construction Manager-at-Risk Agreement (the Contract Form ) a copy of which may be found online at contracts-and-forms/. Construction Manager will provide all Pre-Construction Phase and Construction Phase services necessary to complete the Project on schedule and within budget. Any capitalized term used but not defined in this RFP has the meaning ascribed to it in the Contract Form. B Y SUBMITTING A P ROPOSAL , YOU ARE EXPRESSLY AGREEING TO THE TERMS OF THE C ONTRACT F ORM , WHICH TERMS ARE INCORPORATED HEREIN FOR ALL PURPOSES . 1.3.1 Project pricing shall include a base scope, with both additive and deductive Alternates. Alternates will be developed during the design process and will likely be related to shell space build-out, infrastructure for future growth, etc.

Bid Related Documents

Download Document

Product Code: 95826

Agency Information

Issuing Agency: University of Houston

State: Texas

Agency Type: State and Local

Contact: Purchasing Department, 5000 Gulf Freeway, Bldg. 1, #201, Houston, Texas, 77023



FREE Market Analysis

Get a FREE 90-Day Market Analysis and see the bids you’ve been missing