Government Contract | Texas
New Fire Sprinkler System at E. Cullen Administration Building and Performance Hall

Bid Information

Bid Alert No: 00000443403

Bid Title: New Fire Sprinkler System at E. Cullen Administration Building and Performance Hall

Agency Bid No. Title: RFP730-16056

Received Date: 12/18/2015

Close Date: 01/20/2016

Purchase Type: Final Completion January 01, 2017

Delivery Point:

Delivery Date: Not Stated

Special Notices: Questions Due By 01/05/2016 05:00 PM


Specifications include, but are not limited to:The Project involves all labor, equipment, materials, and supplies required for the installation of a new fire sprinkler system in the Building in accordance with the drawings and specifications prepared by PBK ( t h e Project Architect) dated November 24, 2015, a copy of which is attached hereto and incorporated herein as Exhibit A . Substantial Completion of the Project shall occur on or before November 8, 2016 , time being of the essence. 1.3 Scope of Services, Acceptance of Contract Terms : As further described in Owners standard form Owner-Contractor Agreement (the Contract Form) , which is published online at documents/department-specific-contracts-and-forms/index.php#facilities the respondent t o t h i s R F P ( e a c h , a Respondent) that is ultimately awarded the contract (if any) for the P r o j e c t ( Contractor) will provide construction services necessary to complete the Project within budget and on schedule. BY SUBMITTING A PROPOSAL, RESPONDENT IS EXPRESSLY CONSENTING TO THE TERMS, CONDITIONS

Product Codes: 91468, 91220

Agency Information

Issuing Agency: University of Houston

State: Texas

Agency Type: State and Local

Contact: Maya Thornton 311 E. Cullen, 4800 Calhoun, Houston, Texas, 77204

Phone: 713-743-8269



FREE Market Analysis

Get a FREE 90-Day Market Analysis and see the bids you’ve been missing