Government Contract | Texas
Fleming Drive and Pedestrian Crosswalk

Find Open Contracts in the Architecture and Engineering Industry

Find Contracts Now

Bid Information

Bid Alert No: 00000579559

Bid Title: Fleming Drive and Pedestrian Crosswalk

Agency Bid No. Title: RFP730-16114

Received Date: 05/23/2016

Close Date: 06/09/2016

Purchase Type: Final Completion .10/15/2016

Delivery Point:

Delivery Date: Not Stated

Special Notices: Pre-Bid Conference Mandatory 05/26/2016 09:00 AM, Questions Due By 05/31/2016 01:00 PM


Specifications include, but are not limited to:The Project involves all labor, equipment, materials, and supplies required for Fleming Drive and Pedestrian Crosswalk in accordance with the drawings and specifications prepared by ASA Dally PBK dated February 19, 2016, a copy of which is attached hereto and incorporated herein as Exhibit A. Substantial Completion of the Project shall occur on or before September 19, 2016, time being of the essence.Scope of Services, Acceptance of Contract Terms: As further described in Owners standard form Owner-Contractor Agreement (the Contract Form ), which is published online at the respondent to this RFP (each, a Respondent ) that is ultimately awarded the contract (if any) for the Project ( Contractor ) will provide construction services necessary to complete the Project within budget and on schedule. BY SUBMITTING A PROPOSAL, RESPONDENT IS EXPRESSLY CONSENTING TO THE TERMS, CONDITIONS AND PROVISIONS OF THE CONTRACT FORM. Any capitalized term used but not defined in this RFP has the meaning ascribed to it in the Contract Form

Bid Related Documents

Download Document

Product Codes: 91396, 91395, 91350

Agency Information

Issuing Agency: University of Houston

State: Texas

Agency Type: State and Local

Contact: Tim Henry 4800 Calhoun Road, Houston, Texas, 77004




FREE Market Analysis

Get a FREE 90-Day Market Analysis and see the bids you’ve been missing