Government Contract | Texas
Buildings Lockdown Capabilities

Bid Information

Bid Alert No: 00000524558

Bid Title: Buildings Lockdown Capabilities

Agency Bid No. Title: 759-16-026

Received Date: 03/25/2016

Close Date: 04/26/2016

Purchase Type: Final Completion ....07/04/2016

Delivery Point:

Delivery Date: Not Stated

Special Notices: Pre-Bid Conference Optional 04/11/2016 05:00 PM


Specifications include, but are not limited to:nstallation of access control equipment that will allow lock-down capability for various buildings across campus. This equipment will be operated by the Lenel Onguard access control platform. All exterior doors will have equipment installed or replaced and must be 100% compatible with Lenel OnGuard version 7.0 SP1 (7.0.1067) or later. All equipment must be part of a turnkey solution that will be operated by Lenel Onguard. See scope of work Exhibit A. 1.3Scope of Services; Acceptance of Contract Terms: As further described in Owners standard form Owner-Contractor Agreement, which is found at: (theContract Form) the Contractor, if any, will provide construction services necessary to complete the Project within budget and on schedule. BY SUBMITTING A PROPOSAL,RESPONDENT IS EXPRESSLY CONSENTING TO THE TERMS, CONDITIONS AND PROVISIONS OF THE CONTRACT FORM. Any capitalized term used but not defined in this RFP has the meaning ascribed to it in the Contract Form. BYSUBMITTINGA PROPOSAL, RESPONDENT IS EXPRESSLY CONSENTING TO THE TERMS, CONDITIONS AND PROVISIONS OF THE CONTRACT FORM, INCLUDING THE BOND AND INSURANCE REQUIREMENTS DETAILED IN ARTICLE 12 OF THE CONTRACT. Liquidated damages, as further explained in Section 3.2 of the Contract Form, will be assessed and offset against any amounts due and owing, or that become due, to Contractor as follows: Late Completion Day(s) Per Diem Amount 0-15 250.00 16-30 250.00 31+

Product Codes: 99050, 68002

Agency Information

Issuing Agency: University of Houston-Clear Lake

State: Texas

Agency Type: State and Local

Contact: Jeanne Cumpian, Procurement Department Procurement Department, 2700 Bay Area Blvd., MC137, Houston, Texas, 77058

Phone: 281-283-2150

Fax: 281-283-2156




FREE Market Analysis

Get a FREE 90-Day Market Analysis and see the bids you’ve been missing