Government Contract | Texas
Bayou Building Fume Hoods Renovation B3520

Bid Information

Bid Alert No: 00000517599

Bid Title: Bayou Building Fume Hoods Renovation B3520

Agency Bid No. Title: 759-FMC-1606

Received Date: 03/18/2016

Close Date: 04/12/2016

Purchase Type: Final Completion ........... 07/10/2016

Delivery Point:

Delivery Date: Not Stated

Special Notices: Pre-Bid Conference Optional 03/23/2016 02:00 PM, Questions Due By 03/28/2016 02:00 PM


Specifications include, but are not limited to:Project consists of installation of four new fume hoods with cabinetry (OFCI) into Bayou Building laboratory room 3520. Also installation of one (1) VA V rooftop unit, via RTU (OFCI) and associated equipment including, but not limited to valves, controls and ductwork as specified on construction documents Attachments 1 & 2. The project deadlines are not negotiable. Signed contract to be returned to UHCL within 2 business days of award. Substantial completion 65 calendar days after the Notice to Proceed projected to be 7-1-16. 1.3Scope of Services; Acceptance of Contract Terms: As further described in Owners standard form Owner-Contractor Agreement, which is found at: (theContract Form) the Contractor, if any, will provide construction services necessary to complete the Project within budget and on schedule. BY SUBMITTING A PROPOSAL,RESPONDENT IS EXPRESSLY CONSENTING TO THE TERMS, CONDITIONS AND PROVISIONS OF THE CONTRACT FORM. Any capitalized term used but not defined in this RFP has the meaning ascribed to it in the Contract Form. BY SUBMITTING A PROPOSAL, RESPONDENT IS EXPRESSLY CONSENTING TO THE TERMS, CONDITIONS AND PROVISIONS OF THE CONTRACT FORM, INCLUDING THE BOND AND INSURANCE REQUIREMENTS DETAILED IN ARTICLE 12 OF THE CONTRACT. Liquidated damages, as further explained in Section 3.2 of the Contract Form, will be assessed and offset against any amounts due and owing, or that become due, to Contractor as follows: Late Completion Day(s) Per Diem Amount 0-15 250.00 16-30

Product Code: 91450

Agency Information

Issuing Agency: University of Houston-Clear Lake

State: Texas

Agency Type: State and Local

Contact: Jeanne Cumpian, Procurement Department Procurement Department, 2700 Bay Area Blvd., MC137, Houston, Texas, 77058

Phone: 281-283-2150

Fax: 281-283-2156




FREE Market Analysis

Get a FREE 90-Day Market Analysis and see the bids you’ve been missing